Buffalo law firm focusing on all aspects of commercial law
LPCIMINELLI, INC. v. JPW STRUCTURAL CONTRACTING
| Matter Name: | LPCIMINELLI, INC. v. JPW STRUCTURAL CONTRACTING |
| Client Name: | |
| Case Summary: | Construction manager for extensive renovation project at education center brought action against electrical subcontractor and structural contractor, a potential indemnitor, seeking a determination of amounts owed by or to manager as a result of delays. Subcontractor counterclaimed for breach of contract, seeking, inter alia, a money judgment for additional costs and damages it incurred in relation to the project as a result of the delays. The Supreme Court, Erie County, Timothy J. Walker, A.J., first granted subcontractor's motion for summary judgment on its counterclaim and then entered judgment in favor of subcontractor. Manager and contractor appealed summary judgment order and manager appealed subsequent judgment. |
| Date of Decision | |
| Practice Area |
